Project Information

Bid Title

Hampstead Library Construction Services

Issuing Agency

County of Pender

Location

North Carolina

Published Date

Nov 10, 2025

Closing Date

Dec 18, 2025

Government Level

State & Local

Status

Closed

Ref. #

ITB# 26-408

Original Source

Join to Access Full Details

Bid Inquiries

Join to Access Full Details

Bid Documents

Join to Access Full Details

Project Description

Bid Number:	ITB# 26-408
Bid Title:	Hampstead Library Construction Services
Category:	General Bids
Status:	Open

Description: Sealed proposals will be received until 3:00 p.m. on Thursday, December 18, 2025, at which time they will be publicly opened and read aloud in the boardroom of the Pender County Government Center, 805 S. Walker Street, Burgaw, NC 28425. Submit sealed proposals to the following addresses: By Mail:  Pender County, Attention:  Trisha Newton, PO Box 1578, Burgaw, NC 28425 By UPS/FedEx/Courier: Pender County, Attention: Trisha Newton, 805 S. Walker Street, Burgaw, NC 28425 Clearly mark outside of package with general contractor’s name, license number, and “ITB # 26-408 Hampstead Library Construction Services”. A 5% bid bond is required, and shall be in a separate envelope from the sealed proposal. The contract shall be Single Prime. The work includes construction of a new 20,000 sf library and associated site improvements. Building construction: New work includes wood structure, masonry veneer, building insulation, interior painting, carpet, resilient and tile flooring, and acoustical tile ceilings. The work also includes plumbing, mechanical, electrical, and fire sprinkler. MINORITY BUSINESSES:  Pender County encourages all businesses, including M/WBE, HUB, minority, and women-owned businesses to respond to all Invitations to Bid. An open pre-bid conference will be held for all interested bidders on November 20, 2025 at 2:00 p.m. in the auditorium at Pender County Hampstead Annex, 15060 US-17, Hampstead, NC 28443. The meeting will address project specific questions, issues, bidding procedures, and bid forms. The project site is adjacent to Pender County Hampstead Annex and is available at any time for all contractors and sub-contractors. Additional information and Addenda will be made available to the public by email or on the Architect’s website. The Contractor is responsible for ensuring that their contact information (phone & email) is correct and on file with the person designated below. Requests for substitution must be submitted in writing to the Architect by 5:00 p.m. on December 8, 2025. Requests for clarification or interpretation must be submitted in writing to the Architect by 5:00 p.m. on December 11, 2025. See contact info below. Electronic Contract Documents may be obtained by contacting the Architect, or visiting the architect’s website; s2a3.com/contractors/. No partial sets of the Contract Documents will be issued. Architect Contact: Scott Spike (910) 762-0892 For security reasons, you must enable JavaScript to view this E-mail address. Sawyer Sherwood & Associate 124 Market Street, Wilmington, NC 28401 Pender County reserves the unqualified right to reject any and all proposals. Contractors must be properly licensed. Additional instructions to bidders are included in the Contract Documents. In order to be deemed responsive, the bidder must exemplify the skill, judgment, integrity, sufficient financial resources, and ability necessary to the faithful performance of the construction contract.  The bidder’s Financial Statements may be requested by the County. Publication Date/Time: 11/10/2025 8:00 AM Closing Date/Time: 12/18/2025 3:00 PM

Commodity Codes

• NAICS 236220Commercial and Institutional Building Construction

* Disclaimer: Government BidHub provides information on bids, RFPs (Requests for Proposals), and RFQs (Requests for Qualifications) solely for convenience and informational purposes. This site is not an official public notice board. For official details, responses, or inquiries, please contact the relevant government agency directly.