Project Information

Bid Title

Electrical Services

Issuing Agency

City of Gainesville

Location

Georgia

Published Date

May 28, 2025

Closing Date

Jun 12, 2025

Government Level

State & Local

Status

Closed

Ref. #

25018

Original Source

Join to Access Full Details

Bid Inquiries

Join to Access Full Details

Bid Documents

Join to Access Full Details

Project Description

Bid Number:	25018
Bid Title:	Electrical Services
Category:	Water Resources
Status:	Open

Description: Bid No. 25018 -  Electrical Services Sealed Proposals will be received by the City of Gainesville, Department of Water Resources, 757 Queen City Pkwy, SW, Gainesville, GA.  30501 until (2:00pm)., (June 12, 2025), for the Purchase of (Electrical Services). Bids will be opened at 1006 S. Bradford Street Ext, Gainesville, GA 30501 OVERVIEW The City of Gainesville, Georgia (Hereafter also referred to as “The City”) seeks Proposals to provide (Electrical Services) for its (Department of Water Resources). The City desires to purchase (Electrical Services).  (Electrical Services) is expected to be available for use at the (Department of Water Resources) not later than (July 1, 2025). PROPOSAL CORRESPONDENT Upon Release of this Request for Proposal, all vendor communications concerning this acquisition must be directed to the Administrative Services Department correspondent listed below: For Site visits contact Tim Tench at 678-316-1479 or For security reasons, you must enable JavaScript to view this E-mail address. or Troy Dyer at 404-473-4415 or For security reasons, you must enable JavaScript to view this E-mail address. (Tammy Grier) City of Gainesville 1006 S. Bradford Street, Ext. Gainesville, GA. 30501 Phone: (770.531.2663) FAX: (770.531.2672) ( For security reasons, you must enable JavaScript to view this E-mail address.) Unauthorized contact regarding the proposal with other Gainesville City employees may result in disqualification.   Any oral communications will be considered unofficial and non-binding on the City of Gainesville.  Vendor should rely only on written statements issued by the proposal correspondent. PROPOSAL QUESTIONS All questions must be submitted in writing to the Proposal correspondent named above.  Questions must be received by 10:00 a.m., (06/3/25).  A list of questions and answers will be provided to all know proposers and by request.  Requests may be made to the Proposal correspondent named above. PROPOSAL RESPONSE DATE AND LOCATION The Administrative Services department must receive the vendor’s proposal in a sealed envelope, in its entirety, not later than (June 12, 2025).  2:00pm), Eastern Standard Time in Gainesville, Georgia on (Enter Deadline Date).   Proposals arriving after the deadline will be returned unopened to their senders.  All proposals and accompanying documentation will become the property of the City of Gainesville and may not be returned.  One (1) original and (1) copy of this proposal must be submitted to allow for evaluation.  Proposals must be clearly marked on the outside of the package: Electrical Services Vendors assume the risk of the method of dispatch chosen.  The City of Gainesville assumes no responsibility for delays caused by any delivery service.  Postmarking by the due date will not substitute for actual proposal receipt.   Late proposals will not be accepted nor will additional time be granted to any vendor.  Proposals may not be delivered by facsimile transmission or other telecommunication or solely by electronic means. Proposal Schedule: Proposal Release:                                    (May 21, 2025) Proposal Questions Deadline:             (June 3, 2025 @ 10:00am) Proposal Due Date:                                 (June 12, 2025 @ 2:00pm) WAIVER OF TECHNICALITIES All items must meet or exceed specifications as stated by the City of Gainesville.  The City of Gainesville reserves the right to waive any technicalities and to reject or accept any Proposal in its entirety or to accept any portion thereof if it is determined that either method results in lower costs, better service, final satisfaction or is otherwise determined to be in the best interest of the City of Gainesville. Award may be made by item number or in total.   Determination of best response to proposal will be the sole judgment of the City of Gainesville.  Proposals s remain valid for ninety days for the date of proposal opening. PROPOSAL REJECTION The City of Gainesville reserves the right to reject any or all proposals at any time without penalty. Publication Date/Time: 5/21/2025 7:00 AM Closing Date/Time: 6/12/2025 6:00 PM Related Documents: 25018 Electrical Services-Original - Copy 25018 Electrial Svs-Addendum 1

Commodity Codes

• NAICS 238210Electrical Contractors and Other Wiring Installation Contractors

* Disclaimer: Government BidHub provides information on bids, RFPs (Requests for Proposals), and RFQs (Requests for Qualifications) solely for convenience and informational purposes. This site is not an official public notice board. For official details, responses, or inquiries, please contact the relevant government agency directly.