Project Information

Bid Title

RFP: Rehabilitation of the Andrews Street Bridge Over the Genesee River, Project No. 25213

Issuing Agency

City of Rochester

Location

New York

Published Date

Oct 10, 2024

Closing Date

Oct 18, 2024

Government Level

State & Local

Status

Closed

Original Source

Join to Access Full Details

Bid Inquiries

Join to Access Full Details

Bid Documents

Join to Access Full Details

Project Description

RFP – Rehabilitation of the Andrews Street Bridge Over the Genesee River, Project No. 25213

Download the RFP:

Document

RFP - Andrews Street Bridge Rehab

Download the Record Plans:

1980 Plans:

Document

1980 Andrews Street Bridge Record Plans

2009 Plans:

Document

2009 PM Andrews Street Bridge Maintenance Record Plans

2013 Plans:

Document

2013 Bridge Maintenance Record Plans (Andrews St)

2016 Plans:

Document

2016 Bridge Maintenance Record Plans (Andrews St)

Overview

The City of Rochester Department of Environmental Services Bureau of Architecture and Engineering is soliciting a Request for Proposals (RFP). The City seeks to enter into a Professional Services Agreement for the design and preparation of engineering reports and construction contract documents. This is a federally funded BridgeNY project that includes the design and preparation of engineering reports and construction contract documents for rehabilitation of the Andrews Street Bridge over the Genesee River (BIN 2211280) in the City’s southwest quadrant.

Communications

All communications by parties who have an intent to submit or have submitted a proposal in response to this RFP (“Respondents”), including any questions or requests for clarifications, submission of the proposal, requests for status updates about the proposal selection process and any other inquiries whatsoever concerning this RFP shall be sent, in writing, to the following City contact(s):

Primary Contact/Project Manager:

Tomas Andino, P.E.
tomas.andino@cityofrochester.go v
585-428-6535

Secondary Contact:

Holly E. Barrett, P.E.
holly.barrett@cityofrochester.gov
585-428-6828

No contact is permitted with any other City staff member with regard to this RFP during the RFP process unless specifically authorized in writing. Prohibited contact may be grounds for disqualification.

To ensure that all Respondents have a clear understanding of the scope and requirements of this RFP, the City contact(s) will respond to all timely questions submitted via e-mail to respondents who have provided an e-mail address by the question deadline stated in the RFP and post to the City website for this RFP. The City’s failure to timely respond or provide responses to any questions shall not delay or invalidate the City’s right to make a decision to award an agreement pursuant to this RFP.

The City will make every reasonable effort to keep Respondents informed about the RFP process. Notifications about timeline date changes, amendments to the RFP and other information about the RFP will be sent by e-mail to Respondents and will be posted on the City’s website for this RFP. The City’s failure to provide such information shall not delay or invalidate the City’s right to make a decision to award an agreement pursuant to this RFP.

Pre-Proposal Meeting

A Pre-Proposal Meeting will not be held for this project. Respondents are encourages to visit the project site and may submit questions as needed following the communication guidelines outlined

Submission Delivery Information

Five (5) proposal hard copies and one (1) electronic proposal (preferably via USB storage drive) are to be submitted no later than October 18, 2024 at 4:00 p.m. to:

Holly E. Barrett, P.E.

City Engineer

City of Rochester

Department of Environmental Services,

Bureau of Architecture & Engineering

City Hall, 30 Church Street, Room 300B

Rochester, New York 14614

Commodity Codes

• NAICS 237310Highway, Street, and Bridge Construction

* Disclaimer: Government BidHub provides information on bids, RFPs (Requests for Proposals), and RFQs (Requests for Qualifications) solely for convenience and informational purposes. This site is not an official public notice board. For official details, responses, or inquiries, please contact the relevant government agency directly.