Project Information

Bid Title

Margaret Key Library Parking Lot Renovations

Issuing Agency

Franklin County Courthouse Annex

Location

Florida

Published Date

Apr 2, 2026

Closing Date

May 18, 2026

Government Level

State & Local

Status

Closed

Original Source

Join to Access Full Details

Bid Inquiries

Join to Access Full Details

Bid Documents

Join to Access Full Details

Project Description

Title	End date
Margaret Key Library Parking Lot Renovations	May 18, 2026	Download

Attachment Preview

MARGARET KEY LIBRARY

PARKING LOT IMPROVEMENTS

PROJECT #50189419

NOTICE TO RECEIVE SEALED BIDS

The Franklin County Board of County Commissioners will receive sealed bids from any qualified person,

company or corporation interested in constructing:

MARGARET KEY LIBRARY PARKING LOT IMPROVEMENTS

The project consists of demolishing and constructing/improving a parking lot, concrete ADA parking

spaces, curb and sidewalk reconstruction and striping improvements. This project is located at the

Margaret Key Library in Apalachicola, Fl.

Plans and specifications can be obtained by contacting Shannon Renfro at srenfro@dewberry.com,

Dewberry Engineers, Inc., 324 Marina Drive, Port St. Joe, FL 32456. There is no charge for electronic

plans. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.

Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the

successful bidder. Liquidated damages for failure to complete the project on the specified date will be set

at $250.00 per day.

Please indicate on the envelope that this is a sealed bid, for “MARGARET KEY LIBRARY

PARKING LOT IMPROVEMENTS”.

Bids will be received until 4:30 p.m. eastern time, on May 18th, 2026, at the Franklin County Clerk's

Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and

will be opened and read aloud on May 20th, 2026, at the County Commission meeting held at the

Courthouse Annex Courtroom, 34 Forbes Street, Apalachicola, FL.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or

reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin

County. All bids shall remain firm for a period of sixty days after the opening.

All bidders shall comply with all applicable State and local laws concerning licensing registration and

regulation of contractors doing business to the State of Florida.

If you have any questions, please email D.T. Horton at dthorton@dewberry.com by May 8th, 2026.

ADVERTISEMENT FOR BIDS-00010

Commodity Codes

• NAICS 236220Commercial and Institutional Building Construction
• NAICS 237310Highway, Street, and Bridge Construction
• NAICS 238990All Other Specialty Trade Contractors

* Disclaimer: Government BidHub provides information on bids, RFPs (Requests for Proposals), and RFQs (Requests for Qualifications) solely for convenience and informational purposes. This site is not an official public notice board. For official details, responses, or inquiries, please contact the relevant government agency directly.