Project Information

Bid Title

ADVERTISEMENT FOR BIDS- ISLAND VIEW FRDAP IMPROVEMENTS

Issuing Agency

Franklin County Courthouse Annex

Location

Florida

Published Date

Apr 22, 2026

Closing Date

Jun 2, 2026

Government Level

State & Local

Status

Closed

Original Source

Join to Access Full Details

Bid Inquiries

Join to Access Full Details

Bid Documents

Join to Access Full Details

Project Description

Title	End date
ADVERTISEMENT FOR BIDS- ISLAND VIEW FRDAP IMPROVEMENTS	June 2, 2026	Download

Attachment Preview

FRANKLIN COUNTY ISLAND VIEW PARK FRDAP IMPROVEMENTS PROJECT # 50189044

NOTICE TO RECEIVE SEALED BIDS

The Franklin County Board of County Commissioners will receive sealed bids from any qualified person,

company or corporation interested in constructing:

FRANKLIN COUNTY ISLAND VIEW PARK FRDAP IMPROVEMENTS

Project’s Description: Additions to Island View Park which consist of approximately 743 sq ft of concrete

pad for modular restroom and covered pavilion, A 16’x30’ pre-engineered pole barn for the pavilion

cover, a modular restroom facility and utility connections, etc. Island View Park is located

approximately 1.8 miles east of Carrabelle, Florida.

Electronic copies of the Plans and Specifications can be obtained by contacting Sherry Gayheart at

sgayheart@dewberry.com or at 850.354.5408. The bid must conform to Section 287.133(3) Florida Statutes,

on public entity crimes.

Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the

successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at

$250.00 per day.

Please indicate on the envelope that this is a sealed bid, for “Franklin County Island View Park FRDAP

Improvements”.

Bids will be received until 4:00 p.m. eastern time, on June 1, 2026, at the Franklin County Clerk's Office,

Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be

opened and read aloud on June 3, 2026, at the County Commission meeting at 34 Forbes Street, Apalachicola,

FL.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject

any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All

bids shall remain firm for a period of sixty days after the opening.

All bidders shall comply with all applicable State and local laws concerning licensing registration and

regulation of contractors doing business to the State of Florida. Franklin County encourages Minority Business

Enterprises to respond to this Bid Invitation.

A mandatory pre-bid meeting will be held at the project site on May 14th, 2026, at 10:00 am eastern time.

If you have any questions, please call Erin Griffith at (850) 653-5143. All technical questions must be

addressed in writing and emailed to Erin Griffith at erin@franklincountyflorida.com no later than May 18th,

2026.

ADVERTISEMENT FOR BIDS-00010

Commodity Codes

• NAICS 236220Commercial and Institutional Building Construction

* Disclaimer: Government BidHub provides information on bids, RFPs (Requests for Proposals), and RFQs (Requests for Qualifications) solely for convenience and informational purposes. This site is not an official public notice board. For official details, responses, or inquiries, please contact the relevant government agency directly.