Project Information

Bid Title

Fencing at Flat Creek Plant

Issuing Agency

City of Gainesville

Location

Georgia

Published Date

Dec 10, 2024

Closing Date

Jan 9, 2025

Government Level

State & Local

Status

Closed

Ref. #

Bid No. 25003

Original Source

Join to Access Full Details

Bid Inquiries

Join to Access Full Details

Bid Documents

Join to Access Full Details

Project Description

Bid Number:	Bid No. 25003
Bid Title:	Fencing at Flat Creek Plant
Category:	Water Resources
Status:	Open

Description: City of Gainesville - Invitation for Bid BID No. (25003)  -  Fencing at Flat Creek Plant Sealed Bids will be received by the City of Gainesville, Dept of Water Resources, 757 Queen City Parkway, SW Gainesville, GA.  30501 until (2:00 PM)., 01/09/25), for the Installation of Fencing at Flat Creek Plant. OVERVIEW The City of Gainesville, Georgia (Hereafter also referred to as “The City”) seeks Bids to provide Fencing at Flat Creek Plant for its (Dept of Water Resources Department). The City desires to purchase labor for Fencing at Flat Creek Plant . Fencing is expected to be completed for the (Dept of Water Resources Department) not later than (February 30, 2025)EST BID CORRESPONDENT Upon Release of this Bid, all vendor communications concerning this acquisition must be directed to the Administrative Services Department correspondent listed below: Tammy Grier, City of Gainesville’ Dept of Water Resources, 757 Queen City Pkwy, SW    Phone: (770.531.2663) FAX: (770.531.2672) (For security reasons, you must enable JavaScript to view this E-mail address. ) Tim Tench will act a project manager on this project.  For site visits and addresses, please contact Tim Tench at 678-316-1479, 2641 Old Flowery Branch Road, Gainesville, GA   30504 or For security reasons, you must enable JavaScript to view this E-mail address. Unauthorized contact regarding the Bid with other Gainesville City employees may result in disqualification.  Any oral communications will be considered unofficial and non-binding on the City of Gainesville.  Vendor should rely only on written statements issued by the Bid correspondent. BID QUESTIONS All questions must be submitted in writing to the Bid correspondents named above.  Questions must be received by 10:00 a.m., (12/30/24).  A list of questions and answers will be provided to all know Proposers and by Invitation.  Invitations may be made to the Bid correspondent named above. BID RESPONSE DATE AND LOCATION The Administrative Services department must receive the vendors’ Bid in a sealed envelope, in its entirety, not later than (2:00 pm), Eastern Standard Time in Gainesville, Georgia on 01/09/25.  Bids arriving after the deadline will be returned unopened to their senders.  All Bids and accompanying documentation will become the property of the City of Gainesville and may not be returned.  One (1) original and (1) copy of this Bid must be submitted to allow for evaluation.  Bids must be clearly marked on the outside of the package: (Fencing at Flat Creek Plant  - #25003) Vendors assume the risk of the method of dispatch chosen.  The City of Gainesville assumes no responsibility for delays caused by any delivery service.  Postmarking by the due date will not substitute for actual Bid receipt.   Late Bids will not be accepted nor will additional time be granted to any vendor.  Bids may not be delivered by facsimile transmission or other telecommunication or solely by electronic means. Bid Schedule: Bid Release:                                        12/6/24 Bid Questions Deadline:                     12/30/24 10:00am Bid Due Date:                                      01/09/25, 2:00pm Anticipated Award Date:                    01/09/25 (subject to final Bid review) WAIVER OF TECHNICALITIES All items must meet or exceed specifications as stated by the City of Gainesville.  The City of Gainesville reserves the right to waive any technicalities and to reject or accept any Bid in its entirety or to accept any portion thereof if it is determined that either method results in lower costs, better service, final satisfaction or is otherwise determined to be in the best interest of the City of Gainesville. Award may be made by item number or in total.  Determination of best response to Bid will be the sole judgment of the City of Gainesville.  Bids shall remain valid for ninety days for the date of Bid opening. BID REJECTION The City of Gainesville reserves the right to reject any or all Bids at any time without penalty. Publication Date/Time: 12/6/2024 7:00 AM Closing Date/Time: 1/9/2025 6:00 PM Related Documents: 24011fencingrivsiderfp

Commodity Codes

• NAICS 238990All Other Specialty Trade Contractors

* Disclaimer: Government BidHub provides information on bids, RFPs (Requests for Proposals), and RFQs (Requests for Qualifications) solely for convenience and informational purposes. This site is not an official public notice board. For official details, responses, or inquiries, please contact the relevant government agency directly.